钢筋工个人承包施工合同

钢筋工个人承包施工合同

合同编号： Contract Number

发 包 方： Employer

承 包 方： Contractor

签订时间： Date of Signature

签订地点： Place of Signature

第一条 工程设计技术条件 Article One Technical Conditions of Project Design

第二条 工程承包范围 Scope of Construction

第三条 工程造价 Article Project Cost

第四条 工程设计 Article Four Project Design

第五条 工地代表责任 Article Five Responsibilities of Site Representative

第六条 施工准备 Article Six Execution Preparation

第七条 工程期限 Article Seven Project Term

第八条 工程质量 Article Eight Project Quality

第九条 钢结构材料的供应、 验收 Article Nine Provision / Acceptance of Steel Materials

第十条 工程价款的支付与结算 Article Ten Payment and Settlement of Project Cost

第十一条 施工与设计变更 Article Eleven Alteration of Execution and Design

第十二条 工程验收 Article Twelve Acceptance of Project

第十三条 违约责任 Article Thirteen Responsibilities for Breach

第十四条 纠纷解决办法 Dispute Settlement

第十五条 附则 Article Fifteen Miscellaneous

根据 《建筑法》 规定，为明确双方在履行工程承包合同过程中的权利、义务、程序，经双方协商后，一致同意签订本合同，并依照履行。

For the purpose of stipulation of tittles, liabilities and procedure of project execution hereof for parties hereto, this contract is, through mutual negotiation and agreement by parties hereto, made and entered into for their fulfillment.

第一条 工程设计技术条件 Article One Technical Conditions of Project Design

? 工程名称： Project Name

? 工程地点： Place of Project

? 工程范围及技术要求(本条款内容可作为合同附件列载)

Scope and Technical Requirement of Project (The contents of this clause may be stipulated as Annex hereof).

1 、地质资料由 ___ 提供给设计方

Geographic materials shall be submitted by to the design party.

2 、钢结构建筑抗震等级 Seismic rating of steel structure

3 、建筑设计规格及要求 Specification and requirement of structure design

第二条 工程承包范围 Scope of Construction

一、± 0.000 以上建筑钢结构部分及屋面、墙面(不含砌体和混凝土)，详见第一条相关的内容和最终报价书的报价范围。

Steel structure above ± 0.000, roof and walls ( excluding masonry and concrete), which as detailed the contents and final quotation related to Article One.

二、钢结构原辅材料采购、制造、运输、安装及按现行国家法规应由承包方支付的费用，及发包方委托的钢结构施工图设计。

Procurement, manufacture, transportation and installment of raw / auxiliary materials for steel structure and the cost which should be effected payment by contractor as per existing State’s laws and regulations, and drawings design of project which commissioned by employer.

三、本工程钢结构建筑面积： _______ (平方米)

Construction area of this project is square meters.

四、本工程运输由 ______ 方负责，运费 _____ 在本合同造价内。

Transportation of project shall be liability of , freight of transportation including the project cost herein.

五、本工程基础设计由 ________ 方负责，基础施工由发包方负责并承担费用。

Foundation design shall be liability of , the fees and cost of foundation execution shall be liability of employer and at employer’s cost.

第三条 工程造价 Article Project Cost

工程总造价：人民币 ______ 万元; Total cost of project: RMB YUAN ;

开具发票：材料、制作费 _______ 万元，技术服务及安装费 _______ 万元。

Invoice: The cost of materials and manufacture is RMB YUAN ;

The cost of technical service and installment is RMB YUAN ;

第四条 工程设计 Article Four Project Design

? 发包方责任 Employer’s Responsibilities

1 、发包方负责本工程基础土建的设计。

Design of civil work of project foundation shall be on employer.

2 、发包方委托承包方承担钢结构部分的设计，发包方提供设计所需要的工艺条件及技术条件(详见第一条工程技术条件)并在本合同生效后三天内提供全部相关的技术条件和工艺条件，以供承包方进行设计。

Employer shall commission contractor to assume the design of steel structure, for which employer provide the conditions of craftwork and technique which are necessary to design (dialed reference made to TECHNICAL CONDITIONS OF PROJECT of Article One), in addition to the provisions of all technical conditions and craftworks conditions, within three days upon validity of this contract for contractor’s design.

? 承包方责任 Contractor’s Responsibilities

1 、承包方必须按现行国家钢结构相关规范和发包方提供的相关资料及技术条件进行设计，发包方的超规范要求必须书面告之，承包方在国家规范允许的范围内给予适当倾向量。

Contractor should procethe design in accordance with State’s relevant norms of steel structure and respected materials and technical conditions, if and to the extent that any requirement by employer beyond state’s norms should be given the prior notice to contractor which may make appropriate amount of tendency within allowable arrange of State’s norms.

2 、基础图由承包方设计，发包方提供全部相关资料及技术条件后 ___ 天内，由承包方提供有资质设计院图签的土建基础施工图 套。

Foundation drawings shall be designed by contractor which should, after days of employer’s provision of all relevant materials and technical conditions, provide sets of foundation drawings of civil construction ， which have been approved / signed by the qualified Design Institute ， to employer.

第五条 工地代表责任 Article Five Responsibilities of Site Representative

? 发包方驻工地代表 Employer’s site representative

1 、发包方任命的驻工地代表及其委托代理人由具体管理人员担任，并代表发包方签发有关工程联系单、验收单、结算付款单等。经该代表签署的所有单据具有法律效力，但与本合同条款相冲突的签单无效，以本合同条款为准。

The duties of site representative appointed by and deputy of party A will be assumed by specific managers who shall issue, by or on behalf of employer, relevant Project Connecting Letter, Acceptance Notice and Settlement / Payment Notice, and so on. All documents which issued by such representative shall be in full force and effect, provided that any signed statement by representative conflict to the stipulations hereof shall be null and void, the terms hereof shall prevail.

2 、发包方代表或委托代理人的指令、联系单、通知、须经其本人签名，并以书面形式递交承包方代表，承包方代表在回执上签署姓名、时间后方生效。

No any direction, connecting letter and notice, which are given by site representative appointed by and deputy of party A, shall come into force and effect until have been made the signature of the representative thereon and submit in writing to contractor’s representative who sign its name on return receipt thereof.

第六条 施工准备 Article Six Execution Preparation

? 承包方 By Contractor

1 、在本合同生效后 ______ 日内，由承包方向发包方提供设计图纸 ______ 套，并通知发包方组织设计会审和施工图交底会议，会后 ______ 日内，由发包方提出修改决定，交承包方修改设计，如有设计变更的，则工期视变更情况作相应调整，增减的工程量按报价单计算作相应调整并另签补充合同。

Contractor will, within days after contract coming into force and effect, submit sets of design drawings to employer and a notice for the meeting of joint exam on design and execution drawings. Within days after the meeting, employer shall issue its amendment decision for contractor’s amendment of design. If and to the extension that modification or variation of design made, extension of execution time shall be adjusted correspondingly as the case may be, and all added or minus quantity shall, calculating on Statement of Quotation, be adjusted in addition to complementary contract herewith.

3 、组织原材料采购制造加工，组织施工管理人员和施工机械进常

Organization of the procurement, manufacture and processing, as well as organization of execution managers and machinery acceto the site.

4 、编制施工组织设计或施工方案，材料成品、半成品等进场计划(包括用水、用电计划)送发包方。

Preparation of Design or program of execution, Plan of entering site of material / semi-finished article (including plan of water, electricity supply ) shall be made and submitted to employer.

? 发包方 Employer

1 、合同约定委托承包方设计的项目，在本合同签订的同时，由发包方提供本合同规定的资料及技术条件，供承包方设计，在设计完成后有义务书面确认设计。

With respect to the design item done by contractor commissioned by contract stipulation, employer should, at the same time of this contract conclusion, supply the material and technical conditions, which are stipulated hereby, to contractor for the necessity to design, and have the responsibility of written confirmation on the finished design by contractor.

2 、在承包方进场前做好本工程符合钢结构安装要求的混凝土基础及预埋螺栓并验收合格，同时提供全套土建竣工资料及发包方验收数据的结论。

Employer should, before contractor enter into the site, complete concrete foundation and embedded bolt for this project, which meet the requirements for installation of steel structure, and through acceptance, at same time submit a full set of documents on completion of civil engineering project , and conclusion of data information from employer acceptance.

3 、在承包方进场前，保证本工程施工所需各类车辆进出道路的畅通，接通施工现场的施工用水及照明和动力电源(包括水表、配电板、电表)。

Employer should, before contractor enter into site, ensure the road on which all types of vehicles necessary for project execution smooth and free; and make connection of supply of , on site, water for execution and electricity for lighting and power (including water meter, power distribution panel and power meter).

4 、开工前办理建筑许可证等。如因无建筑许可证而发生的相关责任和一切费用由发包方承担。

Employer should, prior to commencement, procewith Construction Licence and other permissions, if, in the absence of Construction Licence, any relevant responsibility and cost arising there from shall be taken by employer.

第七条 工程期限 Article Seven Project Term

一、本工程钢结构工期自合同签字发包方付达定金之日起 _____ 内完成。其中设计 ____ 天 , 制造 _____天 , 安装自进场起 _____ 天完工。

The project construction should be completed within days as of the date on which earnest money paid by employer making its signature on this contract. days of the construction term for design, days for manufacture and days for installation which calculated from the date on which enter into the site.

二、发包方基础工程完工后，在承包方进场前 ______ 天，发包方应向承包方交付土建验收资料，承包方确认施工现场符合施工要求后，由发包方发出进场通知书，进场安装时间以承包方收到进场通知书后第 ______天起计算。

Employer should, in days prior to contractor’s acceto site after completion of foundation project by employer, delivery the materials of acceptance on civil engineering, and issue Notice of Entering Site to contractor by which the execution site have been confirmed to satisfy the requirements of execution. The time of entering site for installation shall be calculated on and from the day after contractor receive Notice of Entering Site.

第八条 工程质量 Article Eight Project Quality

一、本工程质量要求达到国家相关规范合格标准。

The quality of this project is required to meet State’s respected norms and to reach the eligibility criteria.

二、承包方必须严格按照国家有关规范标准要求精心设计，按照施工图纸、施工说明文件进行施工，接受监理工程师及发包方派驻代表的监督。

Contractor should, in accordance with strictly State’s relevant norms and standards, well-designed and proceexecution as specified on the drawings and explanation for execution, and subject to the surveillance of supervision engineer / site representative on behalf of employer.

第九条 钢结构材料的供应、 验收 Article Nine Provision / Acceptance of Steel Materials

由承包方提供的主要原材料、标准件，必须按有关规定提供产品质量合格证或进行验收合格后方可用于工程。由发包方提供的主要原材料、标准件，也必须有产品质量合格证方可用于工程。钢构主体工程必须经发包方派驻代表检查、验收签章后，方可进行围护结构的安装。

The main raw materials and standard parts which are supplied by contractor should pursuant to relevant specification, be provided with the Product Quality Certification or acceptance before used to project. The main raw materials and standard parts which are supplied by employer are also with the Product Quality Certification before used to project. Steel main project should, after through the exam and acceptance with the signature / seal of employer’s site representative, be processed with the installation of retaining structure.

第十条 工程价款的支付与结算 Article Ten Payment and Settlement of Project Cost

工程价款的支付和结算，根据国家有关部门制定的工程价款结算办法 , 并结合钢结构建筑的特殊情况进行支付与结算。

Payment and settlement of project cost shall, in accordance with the regulations of engineering cost settlement stipulated by State’s authority concerned, and combined with the particular circumstances of steel project, be processed.

一、本工程钢梁、钢柱进场三日内，发包方支付合同总价的 20 %作为工程预付款，计人民币 ____ 万元，承包方开始安装。

Employer should, within three days upon the date of steel beams and steel columns entering into the site, make payment of 20% of total contract cost as project’s advance payment which equal to RMB YUANbefore contractor commence the installation.

二、安装竣工并验收合格后的七天内支付合同总价的 75 %，计人民币 _____ 万元，余款 5 %，计人民币______ 万元作为质保金留滞 , 质保期为一年 , 待质保期满后三日内付清全部质保金。

Employer shall, within seven days on and after installation completion and through acceptance, pay contractor 75% of total contract cost, valued sum of RMB YUAN , and remaining 5% which valued RMB YUAN as retention money withheld for one year of quality warranty, and full retention money shall be released within three days upon expire of warranty period.

三、如因发包方拖欠工程款而影响工程进度，造成承包方的停工，窝工损失的，应由发包方承担相关经济损失，对延误的工期相应延长。

Provided that if employer’s failure of payment of project cost effect the project progreand result in loof contractor’s work suspension and slowdown, on which the responsibilities shall be born by employer and extension of project term for contractor.

四、本合同结算方式：银行即期汇票，结算币种为人民币。

Settlement by Bank Demand Draft, the currency of settlement is RMB.

第十一条 施工与设计变更 Article Eleven Alteration of Execution and Design

一、正式的设计施工图纸、说明和有关技术资料，作为施工的有效依据，开工前由发包方组织设计交底和各方会审，任何一方不得擅自修改。

Formal design drawings, interpretation and relevant technical materials are the effective basis of project execution, for which, prior to commencement, employer shall organize design discussion and joint review by the parties concerned, any party shall not make unilateral alteration.

二、施工中如发现设计的错误或严重不合理的地方，发现方应及时以书面形式通知对方，由提供设计图纸方及时会同有关设计单位研究确定修改意见或变更设计文件，承包方按修改或变更的设计文件进行施工。若因此导致增加费用则由责任方承担，并调整合同造价。

Provided that any discovery of error or substantial unreasonable item in design, the party which discover should in time give written notice to opposite party therewith, and the party by which the design drawings submitted should without undue delay, with concerned design institution, confirm revising opinion of or modification of design document. Contractor shall make execution in accordance with the modified design, and the added cost therefore, if any, shall be on the account of the party with obligation, and contract cost may be adjusted correspondingly.

第十二条 工程验收 Article Twelve Acceptance of Project

一、混凝土基础工程由发包方验收或监理验收合格后在发包方发出《进场开工通知》前交承包方复验。

Concrete foundation project shall, through acceptance of employer or supervision engineer, prior to issuing of Notice of Commencement by employer, delivered to contractor for retesting.

二、钢结构工程验收：按施工图及说明文件、国家现行钢结构工程标准进行验收，验收应在竣工通知发出后五天内开始，逾期不进行验收的，视为验收合格，不影响支付工程款。

Respect to steel structure project: Final acceptance should be made in accordance with drawings, interpretation files and the current national standard for steel structure. Acceptance should, within five days after issuing Completion Notice, be made, if, fail to do so, the project shall be deemed as acceptance and not effect the payment of project cost.

第十三条 违约责任 Article Thirteen Responsibilities for Breach

? 承包方责任： Contractor’s responsibility

一、工程质量不符合设计规定的，负责无偿修理。

Wherever project quality fails to meet the stipulations of design, contractor should make repair in free.

二、因承包方过错不能按合同规定的期限交付使用的，每天按工程总价的万分之五偿付逾期违约金。

Provided that contractor fail to deliver project to use due to the fault of contractor, overdue penalty shall be charged on each delay day by five ten thousandth of total contract cost.

? 发包方的责任： Employer’s responsibility

一、如果发包方不按合同规定拨付工程进度款，对延付金额按照每天万分之五的违约金偿付给承包方，并允许承包方停工，工期相应顺延。

Provided that employer fail to make progrepayment as per contract provisions, deferred amount due to contractor shall be charged with breach penalty by each delay day by five -ten thousandth of the amount payable and allow contractor ‘s suspension in addition to extension of project term accordingly.

二、工程经验收合格或未经验收提前使用后仍不支付工程款的，违约金按总造价每日万分之十支付违约金。

Should employer still refuse to make payment of project cost after through acceptance or advance use without acceptance, breach penalty shall be calculated by each day ten – ten thousandth of total project cost.

‘

第十四条 纠纷解决办法 Dispute Settlement

如果发生与本合同或其任何附件的效力、解释或执行有关的争议，双方首先应争取通过友好协商解决该争议，如果一方向另一方发出通知开始协商之后的__日内，该争议未以此方式解决，则任何一方可将该争议提交仲裁。

In the event any dispute arises in connection with the validity, interpretation, or implementation of this Contract or any of its annexes, the Parties shall attempt in the first instance to resolve such dispute through friendly consultations. If the dispute is not resolved in this manner within _____ days after the date on which one Party has served written notice on the other Party for the commencement of consultations, then either party may refer the dispute to arbitration.

第十五条 附则 Article Fifteen Miscellaneous

一、本合同一式 _______ 份 , 合同附件 _________ 份。甲已双方各执合同正本 ______ 份。与本工程合同有关的施工图纸、招标文件、投标书、中标通知书，履行本合同过程中双方现场代表签署的联系单、指令单、会议纪要等具有合同附件之法律效力。

This contract is make copies of original, with annex copies, parties hereto held

copies of original respectively. Whatever any executing drawings, bidding documents, tender letter, Notice of Acceptance, in addition to, during performance of contract, the contact list, instruction, meeting minutes which are signed by the representatives of parties hereto shall the same validity as contract annex.

二、本合同自双方代表签字，加盖双方公章或合同专用章后成立，收到定金后合同即生效;在工程竣工验收符合要求，保修期满，结算工程款支付完毕后合同终止。

This contract shall, on and from signature of the representatives of parties hereto, be made establishment and shall become effective upon receipt of deposit, and shall cease its validity on and after acceptance in conform with the requirements, expire of warranty period and full payment of project cost.

三、双方已于本合同首页所载日期通过其正式授权的代表签订本合同，以资证明。

IN WITNESS WHEREOF, each of the Parties hereto has caused this Contract to be executed by its duly authorized representative on the date first set forth above.

发包方：(盖章) Employer (Seal) 承包方：(盖章) Contractor (Seal)

法定代表人(签署)： 法定代表人(签署)：

Legal Representative ( Signature ) Legal Representative ( Signature )

技术附件：

Fixing and calibration of anchor bolt for steel structure

钢结构地脚螺栓的固定与校正技术要求

Location of anchor bolt is the first key in the steel construction of this engineering, and shall be specially take care. The location shall be in time and correct to avoid delaying the construction period. After give out axis and frame before installing the embedded parts, cooperate the installing personnel to carry out rechecking for two times when the installation fixing and concrete pouring almost are formed, and adjust the position and elevation to ensure no risk at all.

柱脚螺栓的的精确定位是本工程钢结构施工的第一重点，应特别予以注意。定位要求及时、准确，避免延误工期。在预埋件安装前给出轴线、边框位置后，还要再配合安装人员，在安装固定和砼浇筑即将成型时进行两次复核，及时调整位置、标高，保证万无一失。

The embedding works of anchor bolt parts are responsible by special personnel, set with a special team, included one foreman, one measurer, two welders, two bar placer, and two woodworkers, to be responsible for all embedding works and in charge by the foremen.

预埋件预留工作安排专人负责，设一个专门小组，包括 1 名工长、 1 名测量员、 2 名电焊工、 2 名钢筋工和 2 名木工，负责全部预埋工作，并由工长统一负责。

Anchor bolts shall be processed, piled up in classification, and marked as per the requirements in the drawing beforehand, and be transported to the embedded position in time when the construction reaches the position at where the parts are used.

预埋件提前按图纸要求加工，分类堆放，做好标志，施工到设置使用的部位时，及时运到预埋位置。

Position of anchor bolt is measured from the axis and bounced out the centralized croline by measurer as per the designed requirements, and is placed per the line in setting. Due to the corner iron bracket that fixes the bolt is suspended and leaves a distance from the bottom, shall extend the vertical corner iron up to the upper surface of foundation slab, or increase corner iron bracket to support the bracket of bolt. When positioning, all shall be measured from the axis and must not from the sideline of template to prevent the deflection of embedded parts resulted from the incorrect template position

预埋件位置由测量员按设计要求，从轴线引测，弹出中心十字线，设置时按线安放。由于固定螺栓的角铁支架悬空、不到底，应将竖向角铁加长到基础底板上表面，或增加角铁支架来支撑螺栓支架。定位时应当全部由轴线引测，不得由模板边线引测，防止因模板位置不准导致埋件偏移。

For ensuring the embedded parts fixed securely, may weld them on the structural reinforcement by welder (But shall pay attention to not damage the force carrying reinforcement) to fix its relative position with the template for preventing the inner contraction of embedded parts deflects from the template and embeds into the concrete during concrete pouring. All the uppers of embedded bolts must be drawn through by reinforcement, or steel tube, and corner iron, etc., to ensure them not moved during concrete pouring.

为保证埋件固定牢靠，可用焊机将其焊在结构钢筋上 ( 但应注意不得损伤受力钢筋 ) ，固定其与模板的相对位置，防止在砼浇筑时埋件内缩偏离模板而埋入砼中。预埋螺栓上部必须全部用钢筋或钢管、角铁等全部拉通，确保在砼浇筑过程中不位移。

After embedded, we shall carry out rechecking to ensure the specification and model of embedded parts correct, the embedded position accurate, fixing reliable, and convenient for using.

预埋好后应进行复测检验，保证埋件的规格、型号、正确，预埋位置准确，固定可靠，便于利用。

Construction of embedded parts shall be in tight cooperation with the construction of reinforcement engineering, arrange well the construction sequence, and construct alternately. The embedding works must not affect the construction progreof reinforcement and template engineering. When reinforce the embedded parts, may utilize the existing reinforcement framework, but must not affect the structural requirements of reinforcement engineering, and meanwhile the reinforcing method shall be tidy and beautiful as possible.

预埋件施工要和钢筋工程施工密切配合，安排好施工顺序，穿插施工，预埋工作不得影响钢筋、模板工程的施工进度，预埋件加固时，可利用现有的钢筋骨架，但不得影响钢筋工程的结构要求，同时加固方式力求整齐美观。

The anchor bolts shall be closed by tape, etc., after installed. During the concrete construction, the vibrating rod must not touch the embedded parts, and the embedding team shall follow up for inspection, if any displacement found, calibrate it in time.

柱脚螺栓安装好后，要用胶带等进行封闭保护。混凝土施工时，严禁振动棒碰触埋件，预埋小组要跟踪检查，发现位移及时校正。

Carry out second recheck when the poured concrete just form but still not harden, if any displacement found, must reposition it by adopting measures at once.

Carry out second recheck when the poured concrete just form but still not harden, if any displacement found, must reposition it by adopting measures at once for ensuring the correct position of embedded bolts.

砼浇筑刚成型尚未凝固时，进行第二遍复核，如发现有位移，必须立即采取措施进行复位，以确保预埋螺栓位置的正确。

上一篇：建设工程补充协议书范本  下一篇：没有了

【钢筋工个人承包施工合同】相关文章：

钢筋工的心得05-01

钢筋工的心得04-29

钢筋工的劳务合同范本11-21

钢筋工承包合同04-07

钢筋施工合同范本03-19

钢筋工的劳务合同范本（精选15篇）07-03

风电钢筋施工合同范本02-06

钢筋工程施工要点05-01

钢筋工实训总结（通用10篇）11-01

钢筋工程施工合同书样本（通用5篇）01-15